Contract 21-21 RFT Queen Street Wastewater & Stormwater Improvements

Details

Tender Closed
RFx ID :	24027786
Tender Name :	Contract 21-21 RFT Queen Street Wastewater & Stormwater Improvements
Reference # :	21-21
Open Date :	Monday, 15 March 2021 5:00 PM (Pacific/Auckland UTC+13:00)
Close Date  :	Thursday, 8 April 2021 4:00 PM (Pacific/Auckland UTC+12:00)
Tender Type :	Request for Tenders (RFT)
Tender Coverage :	Sole Agency  [?]
Categories :	72141000 - Highway and road construction services 83101500 - Water and sewer utilities 83101800 - Electric utilities
Regions:	Canterbury Otago
Exemption Reason :	None
Required Pre-qualifications :	None
Contact :	Please use the GETS Q & A.
Alternate Physical Delivery Address  :	125 Queen Street, Waimate 7924, South Canterbury, New Zealand
Alternate Physical Fax Number  :
Agency Address :	125 Queen Street, Waimate, 7924, NEW ZEALAND

Waimate District Council are looking for a Contractor who can meet our requirements for upgrading the wastewater and stormwater in the Waimate CBD. It involves the installation of a stormwater main and laterals as well as wastewater submains and lateral connections to enable a future contract for the relining of the deep main in Queen Street (by others). The contract design is based on a 120-year useful life and we are look for the contract works to be completed in a fit-for-purpose manner.
The scope of works includes:
• Implementation of the Contract including all Health and Safety, Traffic Management, Quality Control, Testing, etc.
• Supply and installation of a new DN150 wastewater system.
• Supply and installation of a new DN225 and DN375 stormwater system.
• Installation of a new fibre duct and laterals.
• Widening of the footpath and realignment of the kerb and channel network to suit the above wastewater and stormwater systems.
• Reinstatement of all affected surfaces.
• New linemarking.
• Removal, storage and reinstatement of all signage and street furniture with new signage where required.

We are looking for a Respondent who can implement proactive strategies which result in cost effective and timely completion of the contract works. Including but not limited to:
• Providing excellent communication with a focus on project managers and site foreman who can understand the contract documents and liaise with Stakeholders effectively.
• Develop and implement innovative work methods and/or materials that result in enhanced performance and cost saving.
• Minimise the disruption to stakeholders who operate in the Waimate Central Business District.
A key expectation of WDC is a Contractor who can work with the local community, minimise disruption to traffic, pedestrians and the business sector. The works are in the Waimate CBD and minimising disruption will be key to the success of the project. Consideration will be given to Contractors who can demonstrate previous experience in similar locations or provide detailed plans on how they will manage construction to minimise disruption to the community.

This tender has been awarded.

• Rooney Earthmoving Ltd - 22, Hilton Highway, Timaru, Timaru, South Canterbury, 7910, NEW ZEALAND
  Value $ 750,000

Award Date: Monday, 9 August 2021 (Pacific/Auckland UTC+12:00)
Date RFx was completed/updated: Saturday, 7 August 2021 4:30 AM (Pacific/Auckland UTC+12:00)