Maunganui Road Safety Improvements

Details

The tenderer shall provide a methodology statement indicating the methodology it proposes to use for the effective and efficient implementation of the Contract Works.
• Site establishment and site security provisions.
• Site plan outlining hoarding, access route, site storage and ablution facilities.
• Proposed construction methods and safe work methodologies. Safe work methodologies shall address Principal’s and Tenderer’s assessed risks in a safe manner throughout project works. Opportunities to eliminate risks or implement substitution or engineering controls shall be included.
• Overall strategy to meet construction targets / completion dates.
• Temporary diversions / relocations or protection works required for utility services affected by the proposed works.
• The division of work (own forces or subcontractor) and how the labour resources are allocated to each work activity (scheduled item).
• Hours of working.
• Explain Respondent’s risk management system to identify, assess and manage significant risks (including emergency procedures) associated with the works (Eliminate and Minimise) and how it will be implemented and kept live for the duration of the contract. Additionally, Respondents shall explain the process of how events such as near misses, incidents or injuries will be reported and investigated.
• A pre-construction risk assessment listing controls for risks and hazards associated with project work. The pre-construction risk assessment shall state at minimum the top 5 Health and Safety risks from Respondent’s perspective and TCC’s key risks as listed below:
• Particular reference should be made to the means of physically isolating all work site activities from public and traffic.
• Methods to reduce the construction disturbance and impact on the public and adjacent property owners including dust and noise control.
• Environmental management methods to manage silt, sedimentation, spills, noise, dust and the protection of trees and vegetation during construction. The tenderer shall demonstrate familiarity with any attached consents and indicate key inspection points in their submitted programme.
• The means of communication on Site between the Contractor's staff and the Engineer. Explain how good coordination, consultation and communication between all PCBUs is established, managed and maintained.